Standard Terms for Purchase Orders
The contract: Only the terms set out in this document shall constitute
the contract between the seller and Four Nordic (know here-in as 4N) for the purchase
of the equipment.
Entry and inspection: The Seller grants to 4N authority for its
servants or agents to enter the premises where the equipment is situated at all
reasonable and prearranged times during business hours and inspect or test the same
making good to the satisfaction of the Seller any damage occasioned by such testing.
Delivery: Delivery of the equipment shall be effected when the
equipment is turned over to the transporter at the place of delivery. Upon delivery
the property of the equipment is turned over to the transporter at the place of
delivery. Upon delivery the property of the equipment shall pass on to 4N and thenceforth
the equipment shall be at the risk of 4N in all respects.
Transport and installation: 4N will undertake at its own expense
the transport, relocation and commissioning of the equipment. 4N shall at its own
expense be fully responsible for all maintenance required to the equipment after
delivery. The Seller will use its best endeavors to give to 4N such assistance as
is able.
Delay: In case the delivery date is exceeded
more than 7 days 4N
is entitled to either cancel the contract and claim damages for losses suffered
or to claim a penalty of 2% of the purchase price each starting week the delivery
is delayed.
Warranties:
The Seller warrants that:
- the equipment in question is sold free of all encumbrances,
liens, charges and claims whatsoever.
- the equipment and all the parts included are of original
manufacture.
- until de-installation the equipment will be duly maintained
and inspected and that the de-installation will be made by the manufacturer unless
otherwise agreed with 4N.
- the equipment - except from reasonable tear and wear will
not be delivered in a condition inferior to its present state of repair to 4N.
- the equipment is, if available, supplied with a valid MAQ-Letter
in accordance with the manufactures rules and regulations or qualifies for maintenance
with the manufacture without further costs to 4N.
- the equipment is supplied with the newest EC-Level.
- the equipment is delivered duly cleaned and wrapped to 4N.
- all equipment comes with a 90 days warranty, for refurbished/used,
and one year for New equipment.
Assistance by the seller: If the Seller agreed
to assist 4N in the delivery and shipping arrangements it shall do so without responsibility,
but shall use all care in such assistance.
Assignment: This contract will not be assignable by the seller
without 4N´s written consent, which 4N shall be entitled to its discretion to refuse.
Settlement of disputes: For purchases from customers in Denmark
any dispute between the two parties shall be settled at the Court of Copenhagen,
notwithstanding that the nature of the dispute may be a High Court case.
For purchases from customers abroad any dispute shall be settled in accordance with
the rules and regulations of the Danish jurisprudence at the Court "Sø- & Handelsretten"
in Copenhagen.
|